Loading...
HomeMy WebLinkAboutMOD Housing - Urban Flats, Phase 1 - Performance Bondlnlt. Bond #1161420 ltAIA Document A312™ -2010 Performance Bond CONTRA CTOR: (Name, legal status and addres~) MOD Housing LLC 4931 McEwan Drive Richland , WA 99352 OWNER: (Name, legal status and addres~) City of Pasco.Washington PO Box 293, 425 N 3rd Avenue Pasco, WA 99301 CON STRU CTI ON CON TRACT Date: Amount : $6 ,787.50 SURETY: (Name, legal status and prinqipal place of business) Arch Insurance Company 1601 Cherry St., 3 Parkway Suite 1500 Philadelphia, PA 19102 Description : "Urban Flats Phase 1, Driveways, Curb Cut & Driveway Approach" (Name and location) BOND Date: 25th October 2019 (Not earlier than Construction Contract Date) Amount: $6 ,787.50 Modifications to this Bond: D See Section 16 SURETY This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable . AIA Document A312-201 o combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. Company: Company: 1 (Corporate Seal) MOD Housing L Arch Insurance Company , r 1-...... I I S ignature: Signatur'!r__;_// 11/ J / J t:J__JLJ_Jj JU ) Name Name Bonnie S. Robbins , Attorney In Fact and Title: and Title: , (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY -Name, address and telephone) AGENT or BROKER: OWNER'S REPRES ENTATI VE : Insurance Office of America 1855 West State Road 434 Longwood, FL 32750 Phone : 407-788-3000 (Architect, Engineer or other party:) AIA Document A312"' -2010. The American Institute of Architects. 0&1110 1 3o o lD lnlt. § 1 Tite Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators. su ccesso rs and assigns to the Owner for the perfo1mance of the Constructio n Contract, which is incorporated herein by reference. § 2 l f the Contractor perfonns the Construction Contract , the Surety and the Contractor shall have no ohl igation under this Bond, except when app licable to participate in a conference as provided in Section 3. § 3 ff there is no Owner Default under th e Construction Cont ract , the Surety 's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Con tractor Default. Such noti ce shall indicate whether the Owner is requesti ng a conference among the Owner, Con tractor and Surety to discuss the Contractor 's perfonnance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend . Unless the Owner agrees otherwise, any conference requested under this Section 3 .1 shall be held within ten ( I 0) business days of the Surety 's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perfonn the Construction Con tract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default ; :2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety ; and ,3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3 , the Surety shall promptly and at the Surety's expense take one of the following actions : § 5.1 Arrange for the Contractor, with the consent of the Owner, to perfonn and complete the Construction Contract ; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors ; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with perfonnance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perfonn and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, dctennine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is detennined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not pro ceed as provided in Section 5 with reasonable promptness , the Surety sha ll be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perfonn its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to th e Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Documanl A312•• -2010. The American lnstllule of Archllec11 . 2 lnlt. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5 .3, then the responsibilities of the Surety to the Owner s hall not be greater than those of the Contractor under the Construction Contract, and the respons ibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subj ect to the commitment by the Owner to pay the Balance of the Co ntract Price, the Surety is obligated, without duplication, for .1 th e responsibilities of the Contractor fo r correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or ifno liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-perfonnance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4 , the Surety's liability is limited to the amount of this Bond. § 9 TI1e Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Cons tru c t ion C ontract., and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated ob ligations. No right o f action shall accrue o n this Bond to any person or entity other than the Owner or its heirs, cxecULors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontr acts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perfonn its obligations under this Bond, whichever occurs first . If the provisions of this Paragraph are void or prohibited by law, the minimum period oflimitat ion available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall l>e mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that thi s Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts rec eived or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. TI1e agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which hes not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents . All the documents that compris e the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement b etween a Contractor and subcontractor, the Lenn C ontracto r in thi s Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to b e Contractor. AIA Document A312"' -2010. The Americ.n lnatl1ute ol Archltect1. 3 lnlt. § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added partfes, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: ______________ Signature: Name and Title: Name and Title: Address Address CAUTION : You ahould algn an orlglnal AIA Contract Document, on which this text appears In RED. An or1gln•I assures that changes will not be obscur•d. AIA Document "312"' -2010. Tll4I A1111rlc&n ll\llitula of Archftlets. 4 lnlt. Bond #1161420 -1AIA Document A312™ -2010 Payment Bond CONTRACTOR : (Name, legal s tatus and address) MOD Housing LLC 4931 McEwan Drive Richland , WA 99352 OWNER : (Name, legal status and address) City of P asco, WA PO B ox 293, 525 N 3rd A v enue Pasco, WA 99301 CONSTRUCTION CONTRACT Date : Amount: $6,787.50 SURETY: (Name, legal status and princ ipal place of business) Arch Insurance Company 1601 Cherry St., 3 Parkway Suite 1500 Philadelphia , PA 19102 This document has important legal consequences . Con sultation with an attorney Is encouraged with re spect to its completio n or modification . Any singular refe rence to Contractor, Surety, Owner or other party shall be conside red plural where applicable. AIA Document A312-201 0 combines two sepa rate bonds, a Performance Bond and a Payment Bond , into on e form. D . . This is not a single combined escnpl todnl: . Performance and Payment Bond. (Name an ocal/on) . C b C D · A h" "Urban F lats Phase 1, Driveways, ur ut, nveway pproac BOND Date: 25th October 2019 (Not earlier than Construct ion Contract Date) Amount: $6,787.50 Modifications to this Bond : ~one D See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: MOD Housing LLC (Corporate Seal) Signature : ___________ Signature : (Corporate Sea~/~ Company J 1 /\_ [\ Jf JL . : ISL) Name Name and Title: and Title: ( Any additional signatures appear o n the last page of this Pay me nt Bond.) (FOR INFORMATION ONLY-Nam e, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Insurance Office of America (Architect, Engineer or other party:) 1855 West State Road 434 Longwood, FL 32750 Phone: 407-788-3000 AIA Doc ument A.312 ,. -2010. The American Institute of Archllecls. 061110 5 lnit. § 1 The Contractor and Surcty,jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 Jf the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and th e Contractor s hall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity s eeking payment for labor, materials or equipment furnished for use in the perfo rmance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit . § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 C laimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furni s hed or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5 . I . I is given by the Owner to the Contractor, that is sufficient to satisfy a C laimant 's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that arc undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have r eached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonab le attorney's fe es the Claimant incurs thereafter to recover any sums found to be due and owing to the C laimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the perfonnancc of the Construction Contract and to satisfy claims, if any, under any construction performance bond . By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Documenl A312"' -2010. The American Institute of Architec ts. 6 lnlt. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (I) on which the C laimant sent a C laim to the Surety pursuant to Section 5.1.2 or 5 .2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of ( 1) or (2) first occurs. If the provisions of thi s Paragraph arc void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When thi s Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be perfonned, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted hercfrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond sha ll be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Constructio n Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any in dividual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's li en may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A312"' -2010. Tho American Institute of Architects. 7 tnft. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perfonn and complete or comply with the other material tenns of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the tenn Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Signature: Name and Title: Address Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes wfll not be obscured. AIA Document A312"' -2010. The American lnsUtute of Architects . 8 AIC 0000286619 THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON BLUE BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Not valid for Note, Loan, Letter of Credit, Currency Rate, Interest Rate or Residential Value Guarantees. POWER OF ATTORNEY Know All Persons By These Presents: That the Arch Insurance Company, a corporation organized and existing under the laws of the State of Missouri. having its principa l administrative office in Jersey City, New Jersey (hereinafter referred to as the "Company") does hereby appoint: Bonnie S. Robbins, Charles P. Boornazian, Nickie L. Sorensen and Taylor M. Pollock of Longwood , FL (EACH) its true and lawful Attorney(s)in-Fact, to make , execute, seal, and deliver from the date of issuance of this power for and on its beha lf as surety, and as its act and deed: Any and all bonds, undertakings, recognizances and other surety obligations, in the pena l sum not exceed ing Ninety Million Dollars ($90,000.000.QQ). This authority does not perm it the same obligation to be split into two or more bonds In order to bring each such bond with in the dollar limit of author ity as set forth herein. The execution of such bonds , undertakings , recogn izances and other surety obligations in pursuance of these presents shall be as binding upon the said Company as fully and amply to all intents and purposes, as if the same had been duly executed and acknowledged by its regularly elected officers at its princ ipal administrative office in Jersey Cily, New Jersey. This Power of Attorney is executed by authority of resolutions adopted by unanimo us consent of the Board of Directors of the Company on September 15, 2011 , true and accurate copies of which are hereinafter set forth and are hereby certified to by t he undersigned Secretary as being in full force and effect: "VOTED, That the Cha irman of the Board, the President , or the Executive Vice President, or any Senior Vice President, of the Surety Business Division, or their appointees designated in writing and filed with the Secretary, or the Secretary shall have the power and authority to appoint agents and attorneys-in-fact, and to authorize them subject to the limitations set forth in their respective powers of attorney, to execute on behalf of the Company , and attach the seal of the Company thereto, bonds, undertakings, recognizances and other surety obligations obl igatory in the nature thereof, and any such officers of the Company may appoint agents for acceptance of process." This Powe r of Attorney is signed , sealed and certified by facsimile under and by authority of the following resolution adopted by the unanimous consent of the Board of Directors of the Company on September 15, 2011: VOTED, That the signature of the Chairman of the Board , the President, or the Executive Vice President, or any Senior Vice President, of the Surety Business Di vision, or their appointees designated in writing and filed with the Secretary, and the signature of the Secretary, the seal of the Company, and certifications by the Secretary, may be affixed by facsimile on any power of attorney or bond executed pursuant to the resolution adopted by the Board of Directors on September 15, 2011 , and any such power so executed, sealed and certified with respect to any bond or undertaking to which it is attached , shall continue to be valid and binding upon the Company. 00ML0013 00 03 03 Page 1 of 2 Printed in U.S .A. AIC 0000286619 In Testimony Whereof, the Company has caused this instrument to be signed and its corporate sea l to be affixed by their au thorized officers, this 12th day of August, 20~. Attested and Certified Patrick K. Nails, Secretary STATE OF PENNSYLVANIA SS COUNTY OF PHILADELPHIA SS Arch Insurance Company I, Michele Tripodi, a Notary Public, do hereby certify that Patrick K. Na ils and David M. Finkelstein personally known to me to be the ~s~riJii., ~ey~2s ilipse names are respectively as Secretary and Executive Wei !'(ejigeht t?'f~he A rch Insurance Company, a ll.<I.o~ppr'atibf\ @rg&nfzed and existing under the laws of the State of Missouri, subsi iJ ~r;J Q.?.t~~f~regpjtlg instrument, appeared before me :rt~ii ~~ [.n ~rs~and severally acknowledged that they being thereunto duly ~tj}~ij~4 ~gne/t f ealed with the corporate seal and "~~v~r~~t~~sa~ ~strument as the free and voluntary act of said corporation an'tl ~~t~~r~p~~fr~Jmd voluntary acts for the uses and p,lJlfPOs.es. th ©"ein set forth. .Q ~ " 2 .; ;; ~ -~ r.i g-J'J 3 ~ COMMONW£ALTHOFP'ENNWY\..VANQJ ~ g :i ~ ~ :-.;:Jc~ "2. bg~~ ~ g ~ c-J HOTAAIAL $UL g c-,,. ::r MIUCEU TRIP004, Holaty P\Jbtlc City ol Ptl~tphla., ffh!U . County M-t CQl'llmlssloll £xpltff July )1, 1011 CERTIFICATION I, Patrick K. Nails, Secretary of the Arch Insurance Company, do hereby certify that the attached Power of Attorney dated August 12. 2019 on behalf of the person(s) as listed above is a true and correct copy and that the same has been in full force and effect since the date thereof and is in full force and effect on the date of this certificate ; and I do further certify that the said David M. Finkelstein , who execu ted the Power of Attorney as Executive Vice President, was on t he date of execution of the attached Power of Attorney the du ly elected Executive Vice President of the Arch Insurance Company. IN p.J!f wu~~~~ ... ,..J,eu/6/.ubscribed my name and affixed the corporate seal of the Arch Insurance Company on thi• --''--_day of'(=-;;J_;;;_x1-==.:=--.c1;;;:::.....::JJ ~ 1 ( • -Pa&i+JU Patrick K. Nails , Secretary This Power of Attorney limits the acts of those named therein to the bonds and undertakings specifically named therein and they have no authority to bind the Company except in the manner and to the extent herein stated. PLEASE SEND ALL CLAIM INQUIRIES RELATING TO THIS BOND TO THE FOLLOWING ADDRESS: Arch Insurance -Surety Division 3 Parkway, Suite 1500 Philadelphia, PA 19102 Page 2 of 2 . . . . . . . . Printed in U.S.A.