Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
Terence Thornhill Architect Agreement Police Building Phase 2
PROFESSIONAL SERVICES AGREEMENT Police Community Services Building (Phase 2) Project THIS AGREEMENT is made and entered into between the City of Pasco, a Washington Municipal Corporation, hereinafter referred to as "City", and Terence L. Thornhill, Architect, Inc, P.S., hereinafter referred to as "Consultant." RECITALS WHEREAS, the City desires to have certain services and/or tasks performed as set forth below requiring specialized skills, training, equipment, and other supportive capabilities; and WHEREAS, the Consultant represents that it is qualified and possesses sufficient skills, experience, equipment, and necessary capabilities, including: technical and professional expertise, when required, to perform the services and/or tasks as set forth in this Agreement upon which the City is relying. NOW, THEREFORE, in consideration of the mutual covenants, and performances contained herein, the parties agree as follows: 1. Scone of Services. The Consultant shall perform such services and accomplish such tasks, including the furnishing of all labor, materials, facilities and equipment necessary for full performance thereof, as identified and designated as Consultant's Responsibilities throughout this Agreement, and as more particularly described in Scope of Work detailed as Exhibit A, and the AIA Standard Form of Agreement, Document 13101 -2007, as Exhibit B, both of which are attached hereto and binding upon the parties and incorporated herein (the "Project "). Provided, however, that in the event that any of the provisions of this Professional Services Agreement are in conflict with the provisions of Exhibit B, the provisions of this agreement shall prevail. 2. Term. This Project shall begin on June 3, 2014, and promptly be completed within six (6) months (December 3, 2014), in accordance with the Scope of Work, Exhibit A. 3. Compensation and Payment. 3.1 Payment for services provided hereunder shall be made following the performance of such services. Such payment shall be full compensation for work performed or services rendered, and for all labor, materials, supplies, equipment, and incidentals necessary to complete the Project. 3.2 No payment shall be made for any services rendered by the Consultant except for services identified and set forth in this Agreement except as may be authorized by a written supplemental agreement approved by the City. Professional Services Agreement- Police Community Services (Phase 2) Project Page 1 a5oa 3.3 The City shall pay the Consultant for work performed under this Agreement upon timely submitted invoices detailing work performed and expenses for which reimbursement is sought. The City shall approve all invoices before payment is issued. Payment shall occur within thirty (30) days of receipt and approval of an invoice. 3.4 The City shall pay the Consultant for all work performed and expenses incurred under this Agreement, as follows. ❑ Hourly (Single Rate): $ per hour plus actual expenses incurred as provided under this Agreement, but not to exceed a total of $ without prior written authorization by the City; or ❑ Hourly (Multiple Rate): Such rates as identified on Exhibit _, plus actual expenses incurred as provided under this Agreement, but not to exceed a total of $ without the prior written authorization by the City; or ® Fixed Sum: A total of $ 550,000; or ® Other: Fixed sum does not include amounts for any additional services which may be agreed to by City and Consultant pursuant to written amendment hereto. 4. Reports and Inspections. 4.1 The Consultant at such times and in such forms as the City may require, shall furnish to the City such statements, records, studies, surveys, reports, data, and information as the City may request pertaining to matters covered by this Agreement. 4.2 The Consultant shall, at any time during normal business hours and as often as the City or the Washington State Auditor may reasonably deem necessary, make available for examination all of its records and data with respect to all matters covered, directly or indirectly, by this Agreement and shall permit the City, or its designated authorized representative to audit and inspect other data relating to all matters covered by this Agreement. The City shall receive a copy of all audit reports made by the agency or firm as to the Consultant's activities. The City may, at its discretion, conduct an audit at its expense, using its own or outside auditors, of the Consultant's activities which relate, directly or indirectly, to this Agreement. Consultant shall be provided a copy of such reports. 4.3 The Consultant, during the term of this Agreement, shall obtain all permits and registration documents necessary for the performance of its work and for the execution of services at its own expense, and shall maintain its validity. Upon request, the Consultant shall deliver to the City copies of these licenses, registration documents, and permits or proof of their issuance or renewal. 4.4 Consultant shall maintain books, records and documents, which sufficiently and properly reflect all direct and indirect costs related to the performance of this Agreement, and shall maintain such accounting procedures and practices as may be Professional Services Agreement- Police Community Services (Phase 2) Project Page 2 necessary to assure proper accounting of all funds paid pursuant to this Agreement. These records shall be subject, at all reasonable times, to inspection, review, or audit as provided above. 4.5 The Consultant shall retain all books, records, documents or other material relevant to this Agreement for three (3) years after its expiration. Consultant agrees that the City, or its designee, shall have full access and right to examine any of said materials at all reasonable times during this period. 5. Ownership and Use of Documents. 5.1 All research, tests, surveys, preliminary data, information, drawings and documents made, collected, or prepared by the Consultant for performing the services subject to this Agreement, as well as any final product, collectively referred to as "work product," shall be deemed as the exclusive property of the City, including copyright as secured thereon. Consultant may not use them except in connection with the performance of the services under this Agreement or with the prior written consent of the City. Any prior copyrighted materials owned by the Consultant and utilized in the performance of the services under this Agreement, or embedded in with the materials, products and services provided thereunder, shall remain the property of the Consultant subject to a license granted to the City for their continued use of the products and services provided under this Agreement. Any work product used by the Consultant in the performance of these services which it deems as "confidential," "proprietary," or a "trade secret" shall be conspicuously designated as such. 5.2 In the event of Consultant's default, or in the event that this Agreement is terminated prior to its completion, the work product of the Consultant, along with a summary of the services performed to date of default or termination, shall become the property of the City, and tender of the work product and summary shall be a prerequisite to final payment under this Agreement. The summary of services provided shall be prepared at no additional cost, if the Agreement is terminated through default by the Consultant. If the Agreement is terminated through convenience by the City, the City agrees to pay Consultant for the preparation of the summary of services provided. 6. Public Records. 6.1 Consultant acknowledges that the City is an agency subject to Chapter 42.56 RCW "Public Records Act." All preliminary drafts or notes prepared or gathered by the Consultant, and recommendations of the Consultant are exempt prior to the acceptance by the City or public citation by the City in connection with City action. 6.2 If the Consultant becomes a custodian of public records of the City and request for such records is received by the City, the Consultant shall respond to the request by the City for such records within five (5) business days by either providing the records, or by identifying in writing the additional time necessary to provide the records with a description of the reasons why additional time is needed. Such additional time shall not exceed twenty (20) business days unless extraordinary good cause is shown. Professional Services Agreement- Police Community Services (Phase 2) Project Page 3 6.3 In the event the City receives a public records request for protected work product of the Consultant within its possession, the City shall, prior to the release of any protected work product or as a result of a public records request or subpoena, provide Consultant at least ten (10) business days prior written notice of the pending release and to reasonably cooperate with any legal action which may be initiated by the Consultant to enjoin or otherwise prevent such release. 7. Independent Contractor Relationship. 7.1 The parties intend that an independent contractor relationship is created by this Agreement. The City is interested primarily in the results to be achieved; subject to the scope of services and the specific requirements of this Agreement, the implementation of services will lie solely with the discretion of the Consultant. No agent, employee, officer or representative of the Consultant shall be deemed to be an employee, agent, officer, or representative of the City for any purpose, and the employees of the Consultant are not entitled to any of the benefits or privileges the City provides for its employees. The Consultant will be solely and entirely responsible for its acts and for the acts of its agents, employees, officers, subcontractors or representatives during the performance of this Agreement. 7.2 In the performance of the services provided in this Agreement, Consultant is an independent contractor with full authority to control and direct the performance of the details of the work, however, the results of the work contemplated herein must meet the approval of the City and shall be subject to the City's general rights of inspection and review to secure the satisfactory completion thereof. 7.3 The Consultant shall comply with all State and Federal laws including, but not limited to: 7.3.1 The definition requirements of RCW 50.04.140 (Employment Security). 7.3.2 RCW 51.08.195 (Industrial Insurance). 7.3.3 Obtain a City of Pasco business license. 7.4 The City may, at its sole discretion, require the Consultant to remove any employee, agent or servant from employment on this Project who, in the City's sole discretion, may be detrimental to the City's interest. 8. Indemnification. 8.1 The Consultant shall defend, indemnify, and hold harmless the City, its officers, officials, agents, employees, and volunteers from any and all claims and causes of action, including, but not limited to, actions of law or administrative proceedings for all injuries to persons or damages to property, and all losses, damages, demands, suits, judgments, including attorney fees, arising out of, or as a result of, or in connection with Professional Services Agreement- Police Community Services (Phase 2) Project Page 4 the work performed under this Agreement, and caused or occasioned in whole or in part by reason of errors, negligent acts or omissions of the Consultant or its subcontractors in the performance of this Agreement, except for injuries and damages caused by the sole negligence of the City, its officers, employees, agents, and volunteers. 8.2 Should a Court of competent jurisdiction determine that this Agreement is subject to RCW 4.24.115, then, in the event of liability for damages arising out of bodily injuries or damages to property caused by or resulting from the concurrent negligence of the Consultant, and the City, its officers, employees, agents and volunteers, the Consultant's liability and obligation to defend hereunder shall only be the proportionate extent of the Consultant's negligence. 8.3 It is further agreed that the indemnification provided herein constitutes the Consultant's waiver of immunity under Industrial Insurance, Title 51 RCW, solely for the purposes of this indemnification. 8.4 No liability shall attach to the City by reason of entering into this Agreement except as expressly provided herein. 8.5 This indemnification shall include damages, penalties and attorney fees sustained as a result of Consultant's delayed or failed performance of Section 6 above. 8.6 This waiver has been mutually negotiated by the parties, and the provisions of this section shall survive the expiration or termination of this Agreement. 9. Insurance. The Consultant shall procure and maintain for the duration of the Agreement, insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Consultant, its agents, representatives, employees, or subcontractors. 9.1 Minimum Scope of Insurance. Consultant shall obtain insurance of the types described below: 9. 1.1 Automobile Liability insurance covering all owned, non - owned, hired and leased vehicles. Coverage shall be written on Insurance Services Office (ISO) form CA 00 01 or a substitute form providing equivalent liability coverage. If necessary, the policy shall be endorsed to provide contractual liability coverage. 9.1.2 Commercial General Liability insurance shall be written on ISO occurrence form CG 00 01 and shall cover liability arising from premises, operations, independent contractors and personal injury and advertising injury. The City shall be named as an insured under the Consultant's Commercial General Liability insurance policy with respect to the work performed for the City. 9.1.3 Workers' Compensation coverage as required by the Industrial Insurance laws of the State of Washington. Professional Services Agreement- Police Community Services (Phase 2) Project Page 5 9.1.4 Professional Liability insurance appropriate to the Consultant's profession. 9.2 Minimum Amounts of Insurance. Consultant shall maintain the following insurance limits: 9.2.1 Automobile Liability insurance with a minimum combined single limit for bodily injury and property damage of $1,000,000 per accident. 9.2.2 Commercial General Liability insurance shall be written with limits no less than: ❑ $1,000,000 each occurrence; ❑ $2,000,000 general aggregate; or ❑ $ each occurrence; and $ general aggregate 9.2.3 Professional Liability insurance shall be written with limits no less than: ® $1,000,000 per claim; ❑ $1,000,000 policy aggregate limit; or ❑ $ per claim; and $ per policy aggregate limit 9.3 Other Insurance Provisions. The insurance policies are to contain, or be endorsed to contain, the following provisions for Automobile Liability, Professional Liability, and Commercial General Liability insurance: 9.3.1 The Consultant's insurance coverage shall be primary insurance as respects the City. Any insurance, self - insurance, or insurance pool coverage maintained by the City shall be excess of the Consultant's insurance and shall not contribute with it. 9.3.2 The Consultant's insurance shall be endorsed to state that coverage shall not be cancelled by either party, except after thirty (30) days prior written notice by certified mail, return receipt requested, has been given to the City. 9.4 Acceptability of Insurers. Insurance is to placed with insurers with a current A.M. Best rating of not less than A: VII. 9.5 Verification of Coverage. Consultant shall furnish the City with original certificates and a copy of the amendatory endorsements, including but not necessarily limited to the additional insured endorsement, evidencing the insurance requirements of the Consultant before commencement of the work. 10. Nondiscrimination. In the performance of this Agreement, the Consultant will not discriminate against any employee or applicant for employment on the grounds of race, creed, color, national origin, sex, marital status, age or the presence of any sensory, mental or physical handicap; provided that the prohibition against discrimination in employment because of handicap shall not apply if the particular disability prevents the proper performance of the particular worker involved. The Consultant shall ensure that applicants are employed, and that Professional Services Agreement- Police Community Services (Phase 2) Project Page 6 employees are treated during employment in the performance of this Agreement without discrimination because of their race, creed, color, national origin, sex, marital status, age or the presence of any sensory, mental or physical handicap. Consultant shall take such action with respect to this Agreement as may be required to ensure full compliance with local, State and Federal laws prohibiting discrimination in employment. 11. Covenant Against Contingent Fees. The Consultant warrants that it has not employed nor retained any company, firm, or person, other than a bona fide employee working exclusively for the Consultant, to solicit or secure this Agreement; and that it has not paid or agreed to pay any company, person or firm, other than a bona fide employee working exclusively for the Consultant, any fee, commission, percentage, brokerage fee, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For breach or violation of this warranty, the City shall have the right to terminate this Agreement. 12. Assignment and Subcontracting. 12.1 The City has awarded this Agreement to the Consultant due to its unique qualifications to perform these services. The Consultant shall not assign (or subcontract other than as specifically identified in Exhibit A) its performance under this Agreement or any portions of this Agreement without the prior written consent of the City, which consent must be sought at least thirty (30) days prior to the date of any proposed assignment. 12.2 Any work or services assigned or subcontracted hereunder shall be subject to each provision of this Agreement including Section 6, Public Records; Section 10, Nondiscrimination; proper bidding procedures where applicable; and all local, State and Federal statutes, ordinances and guidelines. 12.3 Any technical or professional service subcontract not listed in this Agreement, must have prior written approval by the City. 13. Termination. 13.1 Termination for Convenience. Either party may terminate this Agreement for any reason upon giving the other party no less than ten (10) business days written notice in advance of the effective date of such termination. 13.2 Termination for Cause. If the Consultant fails to perform in the manner called for in this Agreement, or if the Consultant fails to comply with any other provisions of this Agreement and fails to correct such noncompliance within five (5) business days of written notice thereof, the City may terminate this Agreement for cause. Termination shall be effected by serving a notice of termination on the Consultant setting forth the manner in which the Consultant is in default. The Consultant will only be paid for services and expenses complying with the terms of this Agreement, incurred prior to termination. 14. General Provisions. Professional Services Agreement- Police Community Services (Phase 2) Project Page 7 14.1 For the purpose of this Agreement, time is of the essence. 14.2 Notice. Notice provided for in this Agreement shall be sent by: 14.2.1 Personal service upon the Project Administrators. 14.2.2 Certified mail to the physical address of the parties, or by electronic transmission to the e-mail addresses designated for the parties below. 14.3 The Project Administrator for the purpose of this Agreement shall be: 14.3.1 For the City: Stan Strebel Deputy City Manager, or his designee 525 North 3rd Pasco WA 99301 strebels@pasco- wa.gov 14.3.2 For the Consultant: Terence Thornhill, Architect, or his designee 9221 Sandifur Parkway, Suite A Pasco, WA 99301 tlt @tltarch.com 15. Dispute Resolution. 15.1 This Agreement has been and shall be construed as having been made and entered into and delivered within the State of Washington, and it is agreed by each party hereto that this Agreement shall be governed by the laws of the State of Washington. 15.2 In the event of a dispute regarding the enforcement, breach, default, or interpretation of this Agreement, the Project Administrators, or their designees, shall first meet in a good faith effort to resolve such dispute. In the event the dispute cannot be resolved by agreement of the parties, said dispute shall be resolved by arbitration pursuant to RCW 7.04A, as amended, with both parties waiving the right of a jury trial upon trial de novo, with venue placed in Pasco, Franklin County, Washington. The substantially prevailing party shall be entitled to its reasonable attorney fees and costs as additional award and judgment against the other. 16. Nonwaiver. Waiver by the City of any provision of this Agreement, or any time limitation provided for in this Agreement, shall not constitute a waiver of any other similar event or other provision of this Agreement. 17. Integration. This Agreement between the parties consists in its entirety of this document and any exhibits, schedules or attachments, as referenced herein. Any modification of this Agreement or change order affecting this Agreement shall be in writing and signed by both parties. Professional Services Agreement- Police Community Services (Phase 2) Project Page 8 18. Authorization. By signature below, each party warrants that they are authorized and empowered to execute this Agreement binding the City and the Consultant respectively. IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the day and year first written above. CITY(OF ]PASCO. WASHINGTON CONSULTANT: Terence Iq Thornhill, Architect, Inc. P.S. Manager eren ornhil ; AP_ r AS TO FORM: Leland B. Kerr, City Attorney Professional Services Agreement- Police Community Services (Phase 2) Project Page 9 m D N c o_ c c sl � - r:s 0 J a ID - �� C N a f n N < -II -Oi, c O n i o L o 0 � s i M � (D C O � rD rD .r C 3 � a (o y, P C � J C d r ro J � T a o *. `" o J m < n o v v v v v Q ° o 0 3 3 3 3 3 rD • J 0o j 1 m rD 3 a CD it = N (D :. a i J a rD o M � a F < N A w O S (D a rD D ° D m J a N fRl ._. aa = < J a < O EL = a < o a c m n a O II (D j D 0 II o C O a ,nc O (D —°. o F 1 K n N VI O d4 (• n C = � o a CL J m m z � a a 1 rf 0 O m fD (D O o n rD N N N N Q (D < n 3 ID D. m m o z a J 3 � m S o a- O a J o 3 a � a C) (D a M 0 O DQ ID 3 ° N M S 3 � c_ no � Q N J o- 20 m r a4 O ZA PA N n s m 3 M n v m w' 7 N W O O 0 W V N N O O O 0 S D) m LM Ez W c n (D o N C ry Cl X 3 3 D 0C CT n O J c n 0 J n 0 T O O N 0 O (D m D 7 N H N 0 N 0 a m CL CS r 0 0 S D J- m n 0 o n n O M T '0 m W cD m O O n O O V A O O W d 01 O O o N A I o n n fD '0 - W cD / O O n O O V O O O d O O O N O O O O O O 0) N O M n' m A O C Sri N m G ri N W C �O_ VY l J A O m x 1P- w N O O 0 MA O• vi A W N w CL a 0 w D z n to °— E a T a O O m r�o O < a o D a = z m m m 0_ m N Z a a ». c O (D 0 Cw O O c � N M O 4 I M. o ~ a a 0 m 3 n C � O O O n N C m M W N o O 3 N N O O m O O 0 c O n ao 3 0 N O O 0 MA O• vi A W N N 0 O o O m °— o ° a a o .N» r�o m o D n m . O_ n O N O n n Cw O O c N M O 4 I M. a m 3 n O 3 O N C m M W O o 3 N O O m O O 0 c c n ao 3 0 ° < O � d m 3 N m N m � n O y m a v a s ti, ° 0 0 < N O A N 3 m d a a O d 0 N C O 3 0 0 c 3 m 7 W Ot O O 0 W , Ol VI A W N N c O D N 6 a .cr O N �" O f�D N N M m d a N w O a 0 o m CL `N° M C= O n _ ID m z aq N.e N N O 00 Q M m n N m < o o < 3 M m m m O m 3 m• C o 3 m vo ,n. 3 � 0 .c+ O O- ° c s o a 0 n N• 3 O N m N m 0 n � O n O m O N 3 � a a < O m 91 a a O d v m N 00 7 O m A O a 3 m 3 N O O O 0 i m N (gyp N W f O °° O O °o 0 0 0 r a 0 S m n Q m N 00 0 O N 0 C0 G_ 0 a a 0 d A E G: I (D CL 0 6 (D M m 3 O 3 CL W N O 3 W -I (D G .w N ry w � C p CL p m o " 3 O N 3 fD N N n D < m o v A rD m n M OQ K o cr c a > O O N mO_ S < w 3 m tD p CD � or fD fD M a c (o a a- w n d T O O W d VI n fD G A VI Gl 3 Q 'O v m ao' 3 n Q O_ O 3 N fD G n m �rV ul O O O O C O W N N n z v (n O G ? C n S N O ^ r. m RO -pi. c N c O" n O 3 m 0 O 0 O C N O O 0 im N O 0 O 0 0 W, D 0 C A » � O A 3 a 3 3 M 0 3 N V O O 0 s N A OD Ln O O 0 0 ry N T O CL D m � m fD p Q 2 s N <, m a r6D pi O D p n 0 0 3 3 0 3 m 3 (D N N c O * ] ' 7 '-O ^ p 'p c O p 2L N W, D 0 C A » � O A 3 a 3 3 M 0 3 N V O O 0 s N A OD Ln O O 0 0 T m O WO N C Q n � o m < O 3 m N m N 3 3 o O n w c o D � � s r: m f0 N c m 0 O N m � � (D v � m x N N N m O m � m D 3 � D (D N W O O o v ^ m m n m n � •C O � O C S (=1 N O m N N O m � a Q m N w_ m n O 3 m 3 O_ m re O O D � fl- c o m � a v O m O n O s D m O rmo 3 m m M O n fD N � rt w O � m m � N O m � O O o � S m d o_ a o 0 0 � o w m N — m m < < n n m D m T D N O. O C o Q .+ O d D N f0 N O a 3 < o m c N aSi W O v m 0 n rr m O n n d � M D' fD N d N O S N w m <o (D m G K °w m 0 °1 O a S a m M N O n S 0 0 c O m n O 3 � O C� O S w D D 0 N r x* e+ x• r r r r r W N r O m 3 O O s y N n w H A d O O O F y � 3 G p .Oi � - ^• vOi N O 9 W h c 0 N m x, w H G 'O n .O. w � 3 r•F � C! � n n O R 3 c n n p m m N 01 M M 0 G O D .O d O n. W n n m m � m O n m N d N C LO O 0 w pC V Of T T G uW M i m m m 3 G n pD 7, 7 m n a N S 0 oR a m m \ C a o m m n IA e3+ N O w O M m 0 3 a m Oq 7 O O G O O N N m d R N n. 'o d d w m N 3 a N 3 m N 0 z 0 S m m n N a n T J m N ' a f- �Ktstr 8 1A Document B101Tt - 2007 Standard Form of Agreement Between Owner and Architect AGREEMENT made as of the 12th day of June in the year 2014 (In words, indicate day, month and year) BETWEEN the Architect's client identified as the Owner: ADDITIONS AND DELETIONS: (Name, legal status, address and other information) The author of this document has added information needed for its City of Pasco completion. The author may also 525 N. 3 rd rd Ave. ve. have revised the text of the original Pasco, AIA standard form. An Additions and Pasco, WA 99301 Deletions Report that notes added information as wail as revisions to the standard form text is available and the Architect: from the author and should be (Name, legal status, address and other information) reviewed. A vertical line in the left margin of this document indicates Terence L. Thornhill, Architect, Inc. P.S. where the author has added 9221 Sandifur Pkwy, Suite A, necessary information and where Pasco, WA 99301 the author has added to or deleted from the original AIA text. for the following Project: This document has important legal (Name, location and detailed description) consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Pasco Police Community Services Building 525 N. 3rd Ave. Pasco, WA 99301 The Owner and Architect agree as follows. AIA Document 6101 - —2007 (formerly Bil TM —1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights Init. reserved. WARNING: This AIA® Document is protected by U.S. Copyright Lew and Into mational Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible 1 under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (389ADA2C) TABLE OF ARTICLES 1 INITIAL INFORMATION 2 ARCHITECT'S RESPONSIBILITIES 3 SCOPE OF ARCHITECT'S BASIC SERVICES 4 ADDITIONAL SERVICES 5 OWNER'S RESPONSIBILITIES 6 COST OF THE WORK 7 COPYRIGHTS AND LICENSES 8 CLAIMS AND DISPUTES 9 TERMINATION OR SUSPENSION 10 MISCELLANEOUS PROVISIONS 11 COMPENSATION 12 SPECIAL TERMS AND CONDITIONS 13 SCOPE OF THE AGREEMENT EXHIBIT A INITIAL INFORMATION ARTICLE 1 INITIAL INFORMATION § 1.1 This Agreement is based on the Initial Information set forth in this Article I and in optional Exhibit A, Initial Information: (Complete Exhibit A, Initial Information, and incorporate it into the Agreement at Section 13.2, or state below Initial Information such as details of the Project's site and program, Owner's contractors and consultants, Architect's consultants, Owner's budget for the Cost of the World authorized representatives, anticipated procurement method, and other information relevant to the Project.) § 1.2 The Owner's anticipated dates for commencement of construction and Substantial Completion of the Work are set forth below: .1 Commencement of construction date: Anticipated construction start is March 2015 .2 Substantial Completion date: Anticipated construction finish is March 2016 § 1.3 The Owner and Architect may rely on the Initial Information. Both parties, however, recognize that such information may materially change and, in that event, the Owner and the Architect shall appropriately adjust the schedule, the Architect's services and the Architect's compensation. ARTICLE 2 ARCHITECT'S RESPONSIBILITIES § 2.1 The Architect shall provide the professional services as set forth in this Agreement. Init. AIA Document 8101 TM — 2007 (fonnerly 8761 TM — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAe Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/1212014 under Order No.4594859925 which expires on 06/12/2015, and is not for resale. User Notes: (3a9ADA2C) § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner's knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect's professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance for the duration of this Agreement. If any of the requirements set forth below exceed the types and limits the Architect normally maintains, the Owner shall reimburse the Architect for any additional cost: (Identify types and limits of insurance coverage, and other insurance requirements applicable to the Agreement, if any.) .1 General Liability Please see attached .2 Automobile Liability Please see attached .3 Workers' Compensation Please see attached .4 Professional Liability Please see attached ARTICLE 3 SCOPE OF ARCHITECT'S BASIC SERVICES § 3.1 The Architect's Basic Services consist of those described in Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Additional Services. § 3.1.1 The Architect shall manage the Architect's services, consult with the Owner, research applicable design criteria, attend Project meetings, communicate with members of the Project team and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner's consultants. The Architect shall be entitled to rely on the accuracy and completeness of services and information famished by the Owner and the Owner's consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner's review, for the performance of the Owner's consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner's approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. Init. AIA Documerd 8101 TM —2007 (formerly BIB" — 1997). Copydght ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAO Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAe Document, or any portion of It, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order NoAS94859925 which expires on 06112/2015, and is not for resale. User Notes: (3B9ADA2C) § 3.1.4 The Architect shall not be responsible for an Owner's directive or substitution made without the Architect's approval. § 3.1.5 The Architect shall, at appropriate times, contact the governmental authorities required to approve the Construction Documents and the entities providing utility services to the Project. In designing the Project, the Architect shall respond to applicable design requirements imposed by such governmental authorities and by such entities providing utility services. § 3.1.6 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project. § 3.2 SCHEMATIC DESIGN PHASE SERVICES § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect's services. § 3.2.2 The Architect shall prepare a preliminary evaluation of the Owner's program, schedule, budget for the Cost of the Work, Project site, and the proposed procurement or delivery method and other Initial Information, each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. § 3.2.3 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. § 3.2.4 Based on the Project's requirements agreed upon with the Owner, the Architect shall prepare and present for the Owner's approval a preliminary design illustrating the scale and relationship of the Project components. § 3.2.5 Based on the Owner's approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner's approval. The Schematic Design Documents shall consist of drawings and other documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital modeling. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. § 3.2.5.1 The Architect shall consider environmentally responsible design alternatives, such as material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner's program, schedule and budget for the Cost of the Work. The Owner may obtain other environmentally responsible design services under Article 4. § 3.2.5.2 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics, in developing a design for the Project that is consistent with the Owner's program, schedule and budget for the Cost of the Work. § 3.2.6 The Architect shall submit to the Owner an estimate of the Cost of the Work prepared in accordance with Section 6.3. § 3.2.7 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner's approval. § 3.3 DESIGN DEVELOPMENT PHASE SERVICES § 3.3.1 Based on the Owner's approval of the Schematic Design Documents, and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner's approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and Ink AIA Document 8101 - —2007 (formerly B1611-- 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA- Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 4 this AIA® Document, or any portion of It may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible ( under the law. This document was produced by AIA software at 17:15:51 on 06112/2014 under Order No.4594859925 which expires on 061122015, and is not for resale. User Notes: (3B9ADA2C) electrical systems, and such other elements as may be appropriate. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish in general their quality levels § 3.3.2 The Architect shall update the estimate of the Cost of the Work. § 3.3.3 The Architect shall submit the Design Development Documents to the Owner, advise the Owner of any adjustments to the estimate of the Cost of the Work, and request the Owner's approval. § 3.4 CONSTRUCTION DOCUMENTS PHASE SERVICES § 3.4.1 Based on the Owner's approval of the Design Development Documents, and on the Owner's authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner's approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that in order to construct the Work the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4. § 3.4.2 The Architect shall incorporate into the Construction Documents the design requirements of governmental authorities having jurisdiction over the Project. § 3.4.3 During the development of the Construction Documents, the Architect shall assist the Owner in the development and preparation of (1) bidding and procurement information that describes the time, place and conditions of bidding, including bidding or proposal forms; (2) the form of agreement between the Owner and Contractor; and (3) the Conditions of the Contract for Construction (General, Supplementary and other Conditions). The Architect shall also compile a project manual that includes the Conditions of the Contract for Construction and Specifications and may include bidding requirements and sample fortes. § 3.4.4 The Architect shall update the estimate for the Cost of the Work. § 3.4.5 The Architect shall submit the Construction Documents to the Owner, advise the Owner of any adjustments to the estimate of the Cost of the Work, take any action required under Section 6.5, and request the Owner's approval. § 3.5 BIDDING OR NEGOTIATION PHASE SERVICES § 3.5.1 GENERAL The Architect shall assist the Owner in establishing a list of prospective contractors. Following the Owner's approval of the Construction Documents, the Architect shall assist the Owner in (1) obtaining either competitive bids or negotiated proposals; (2) confirming responsiveness of bids or proposals; (3) determining the successful bid or proposal, if any; and, (4) awarding and preparing contracts for construction. § 3.5.2 COMPETITIVE BIDDING § 3.5.2.1 Bidding Documents shall consist of bidding requirements and proposed Contract Documents. § 3.5.2.2 The Architect shall assist the Owner in bidding the Project by .1 procuring the reproduction of Bidding Documents for distribution to prospective bidders; .2 distributing the Bidding Documents to prospective bidders, requesting their return upon completion of the bidding process, and maintaining a log of distribution and retrieval and of the amounts of deposits, if any, received from and returned to prospective bidders; .3 organizing and conducting a pre -bid conference for prospective bidders; .4 preparing responses to questions from prospective bidders and providing clarifications and interpretations of the Bidding Documents to all prospective bidders in the form of addenda; and .5 organizing and conducting the opening of the bids, and subsequently documenting and distributing the bidding results, as directed by the Owner. § 3.5.2.3 The Architect shall consider requests for substitutions, if the Bidding Documents permit substitutions, and shall prepare and distribute addenda identifying approved substitutions to all prospective bidders. Init. AIA Document B101 -- 2007 tformerly 8151 -- 1997). Copyright 01974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This Document was produced by AIA software at 17:15:51 on 06/12/2014 under Order No.4594859925 which expires on 0611212015, and is not for resale. User Notes: (3139ADA2C) § 3.5.3 NEGOTIATED PROPOSALS § 3.5.3.1 Proposal Documents shall consist of proposal requirements and proposed Contract Documents. § 3.5.3.2 The Architect shall assist the Owner in obtaining proposals by .1 procuring the reproduction of Proposal Documents for distribution to prospective contractors, and requesting their return upon completion of the negotiation process; .2 organizing and participating in selection interviews with prospective contractors; and .3 participating in negotiations with prospective contractors, and subsequently preparing a summary report of the negotiation results, as directed by the Owner. § 3.5.3.3 The Architect shall consider requests for substitutions, if the Proposal Documents permit substitutions, and shall prepare and distribute addenda identifying approved substitutions to all prospective contractors. § 3.6 CONSTRUCTION PHASE SERVICES § 3.6.1 GENERAL § 3.6.1.1 The Architect shall provide administration of the Contract between the Owner and the Contractor as set forth below and in AIA Document A20P''M -2007, General Conditions of the Contract for Construction. If the Owner and Contractor modify AIA Document A201 -2007, those modifications shall not affect the Architect's services under this Agreement unless the Owner and the Architect amend this Agreement. § 3.6.1.2 The Architect shall advise and consult with the Owner during the Construction Phase Services. The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement. The Architect shall not have control over, charge of, or responsibility for the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, nor shall the Architect be responsible for the Contractor's failure to perform the Work in accordance with the requirements of the Contract Documents. The Architect shall be responsible for the Architect's negligent acts or omissions, but shall not have control over or charge of; and shall not be responsible for, acts or omissions of the Contractor or of any other persons or entities performing portions of the Work. § 3.6.1.3 Subject to Section 4.3, the Architect's responsibility to provide Construction Phase Services commences with the award of the Contract for Construction and terminates on the date the Architect issues the final Certificate for Payment. § 3.6.2 EVALUATIONS OF THE WORK § 3.6.2.1 The Architect shall visit the site at intervals appropriate to the stage of construction, or as otherwise required in Section 4.3.3, to become generally familiar with the progress and quality of the portion of the Work completed, and to determine, in general, if the Work observed is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect shall not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the Work. On the basis of the site visits, the Architect shall keep the Owner reasonably informed about the progress and quality of the portion of the Work completed, and report to the Owner (1) known deviations from the Contract Documents and from the most recent construction schedule submitted by the Contractor, and (2) defects and deficiencies observed in the Work. § 3.6.2.2 The Architect has the authority to reject Work that does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable, the Architect shall have the authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents, whether or not such Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractors, material and equipment suppliers, their agents or employees or other persons or entities performing portions of the Work. § 3.6.2.3 The Architect shall interpret and decide matters concerning performance under, and requirements of, the Contract Documents on written request of either the Owner or Contractor. The Architect's response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness. Init. AIA Document 811011--2007 (formerly 1311611- — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAe Document Is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of It may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/1212014 under Order No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (3B9ADA2C) § 3.6.2A Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both Owner and Contractor, shall not show partiality to either, and shall not be liable for results of interpretations or decisions rendered in good faith. The Architect's decisions on matters relating to aesthetic effect shall be final if consistent with the intent expressed in the Contract Documents. § 3.6.2.5 Unless the Owner and Contractor designate another person to serve as an Initial Decision Maker, as that term is defined in AIA Document A201 -2007, the Architect shall render initial decisions on Claims between the Owner and Contractor as provided in the Contract Documents. § 3.6.3 CERTIFICATES FOR PAYMENT TO CONTRACTOR § 3.6.3.1 The Architect shall review and certify the amounts due the Contractor and shall issue certificates in such amounts. The Architect's certification for payment shall constitute a representation to the Owner, based on the Architect's evaluation of the Work as provided in Section 3.6.2 and on the data comprising the Contractor's Application for Payment, that, to the best of the Architect's knowledge, information and belief, the Work has progressed to the point indicated and that the quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject (1) to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, (2) to results of subsequent tests and inspections, (3) to correction of minor deviations from the Contract Documents prior to completion, and (4) to specific qualifications expressed by the Architect. § 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made exhaustive or continuous on -site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment, or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. § 3.6.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment. § 3.6.4 SUBMITTALS § 3.6.4.1 The Architect shall review the Contractor's submittal schedule and shall not unreasonably delay or withhold approval. The Architect's action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time in the Architect's professional judgment to permit adequate review. § 3.6.4.2 In accordance with the Architect- approved submittal schedule, the Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. Review of such submittals is not for the purpose of determining the accuracy and completeness of other information such as dimensions, quantities, and installation or performance of equipment or systems, which are the Contractor's responsibility. The Architect's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect, of any construction means, methods, techniques, sequences or procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 3.6.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or certifications by a design professional related to systems, materials or equipment, the Architect shall specify the appropriate performance and design criteria that such services must satisfy. The Architect shall review Shop Drawings and other submittals related to the Work designed or certified by the design professional retained by the Contractor that bear such professional's seal and signature when submitted to the Architect. The Architect shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications and approvals performed or provided by such design professionals. § 3.6.4.4 Subject to the provisions of Section 4.3, the Architect shall review and respond to requests for information about the Contract Documents. The Architect shall set forth in the Contract Documents the requirements for requests Init. AIA Document 8101 ° —2007 (formerly 5161- — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAs Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/1212014 under Order No.4594859925 which expires on 0611212015, and is not for resale. User Notes: (3139ADA2C) for information. Requests for information shall include, at a minimum, a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested. The Architect's response to such requests shall be made in writing within any time limits agreed upon, or otherwise with reasonable promptness. If appropriate, the Architect shall prepare and issue supplemental Drawings and Specifications in response to requests for information. § 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents. § 3.6.5 CHANGES IN THE WORK § 3.6.5.1 The Architect may authorize minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. Subject to the provisions of Section 4.3, the Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents. § 3.6.5.2 The Architect shall maintain records relative to changes in the Work. § 3.6.6 PROJECT COMPLETION § 3.6.6.1 The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; issue Certificates of Substantial Completion; receive from the Contractor and forward to the Owner, for the Owner's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor; and issue a final Certificate for Payment based upon a final inspection indicating the Work complies with the requirements of the Contract Documents. § 3.6.6.2 The Architect's inspections shall be conducted with the Owner to check conformance of the Work with the requirements of the Contract Documents and to verify the accuracy and completeness of the list submitted by the Contractor of Work to be completed or corrected. § 3.6.6.3 When the Work is found to be substantially complete, the Architect shall inform the Owner about the balance of the Contract Sum remaining to be paid the Contractor, including the amount to be retained from the Contract Sum, if any, for final completion or correction of the Work. § 3.6.6.4 The Architect shall forward to the Owner the following information received from the Contractor: (1) consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment; (2) affidavits, receipts, releases and waivers of liens or bonds indemnifying the Owner against liens; and (3) any other documentation required of the Contractor under the Contract Documents. § 3.6.6.5 Upon request of the Owner, and prior to the expiration of one year from the date of Substantial Completion, the Architect shall, without additional compensation, conduct a meeting with the Owner to review the facility operations and performance. ARTICLE 4 ADDITIONAL SERVICES § 4.1 Additional Services listed below are not included in Basic Services but may be required for the Project. The Architect shall provide the listed Additional Services only if specifically designated in the table below as the Architect's responsibility, and the Owner shall compensate the Architect as provided in Section 11.2. (Designate the Additional Services the Architect shall provide in the second column of the table below. In the third column indicate whether the service description is located in Section 4.2 or in an attached exhibit. If in an exhibit, identify the exhibit.) Additional Services: See Section 4.2 Below Responsibility (Architect, Owner or Not Provided) Location of Service Description (Section 4.2 below or in an exhibit attached to this document and identified below 4.1.1 Programming B202T"L2009 4.1.2 Multiple preliminary designs 4.1.3 Measured drawings 4.1.4 Existing facilities surveys Init. AIA Document 13101--2007 (formerly 8161 - — 1997). Copydght ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible t under the law. This document was produced by AIA software at 17:15:51 on 0611212014 under Order No.4594859925 which expires on 06/12/2015, and is not for resale. User Notes: (369ADA2C) 4.1.5 Site Evaluation and Plannin 203Tm -2007 § 4.1.6 Building Information Modeling (E202Tm- 2008 4.1.7 Civil engineering 4.1.8 Landscape design 4.1.9 Architectural Interior Design 252Th7 -2007 4.1.10 Value Analysis B204Tm -2007 4.1.11 Detailed cost estimating § 4.1.12 On -site Project Representation (B207 rm- 2008 4.1.13 Conformed construction documents CCU As-Designed Record drawings 4.1.15 As- Constructed Record drawings 4.1.16 Post occupancy evaluation 4.1.17 Facility Support Services 210Tm -200 4.1.18 Tenant - related services 4.1.19 Coordination of Owner's consultants 4.1.20 Telecommunications /data design § 4.1.21 Security Evaluation and Planning (B206TM- 2007 4.1.22 Commissioning 211Tm -2007 4.1.23 Extensive environmentally responsible design 4.1.24 LEEDO Certification B214Tm -2012 4.1.25 Fast -track design services 4.1.26 Historic Preservation 205ThL2007 § 4.1.27 Furniture, Furnishings, and Equipment Design 11253T^L2007 § 42 Insert a description of each Additional Service designated in Section 4.1 as the Architect's responsibility, if not further described in an exhibit attached to this document. All additional services to be evaluated on a case by case basis with attached additional services agreement (EXMIT. f, to be submitted and approved prior to all additional work commencing. 6 -1 § 4.3 Additional Services may be provided after execution of this Agreement, without invalidating the Agreement. Except for services required due to the fault of the Architect, any Additional Services provided in accordance with this Section 4.3 shall entitle the Architect to compensation pursuant to Section 11.3 and an appropriate adjustment in the Architect's schedule. § 4.3.1 Upon recognizing the need to perform the following Additional Services, the Architect shall notify the Owner with reasonable promptness and explain the facts and circumstances giving rise to the need. The Architect shall not proceed to provide the following services until the Architect receives the Owner's written authorization: .1 Services necessitated by a change in the Initial Information, previous instructions or approvals given by the Owner, or a material change in the Project including, but not limited to, size, quality, complexity, the Owner's schedule or budget for Cost of the Work, or procurement or delivery method; .2 Services necessitated by the Owner's request for extensive environmentally responsible design alternatives, such as unique system designs, in -depth material research, energy modeling, or LEED® certification; .3 Changing or editing previously prepared Instruments of Service necessitated by the enactment or revision of codes, laws or regulations or official interpretations; .4 Services necessitated by decisions of the Owner not rendered in a timely manner or any other failure of performance on the part of the Owner or the Owner's consultants or contractors; .5 Preparing digital data for transmission to the Owner's consultants and contractors, or to other Owner authorized recipients; .6 Preparation of design and documentation for alternate bid or proposal requests proposed by the Owner; Init. ALA Document 13101- —2007 (formerly 8151- — 1887). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights re served. WARNING: This AIAe Document Is protected by U.B. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAe Document, or any portion of it may result in severe civil and criminal pennies, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order No.4594859925 which expires on 0611212015, and is not for resale. User Notes: (399ADA2C) .7 See EXHIBIT A, Note F. .8 Preparation for, and attendance at a dispute resolution proceeding or legal proceeding, except where the Architect is party thereto; .9 Evaluation of the qualifications of bidders or persons providing proposals; .10 Consultation concerning replacement of Work resulting from fire or other cause during construction; or .11 Assistance to the Initial Decision Maker, if other than the Architect. § 4.3.2 To avoid delay in the Construction Phase, the Architect shall provide the following Additional Services, notify the Owner with reasonable promptness, and explain the facts and circumstances giving rise to the need. If the Owner subsequently determines that all or parts of those services are not required, the Owner shall give prompt written notice to the Architect, and the Owner shall have no further obligation to compensate the Architect for those services: 1 Reviewing a Contractor's submittal out of sequence from the submittal schedule agreed to by the Architect; .2 Responding to the Contractor's requests for information that are not prepared in accordance with the Contract Documents or where such information is available to the Contractor from a careful study and comparison of the Contract Documents, field conditions, other Owner- provided information, Contractor - prepared coordination drawings, or prior Project correspondence or documentation; .3 Preparing Change Orders and Construction Change Directives that require evaluation of Contractor's proposals and supporting data, or the preparation or revision of Instruments of Service; .4 Evaluating an extensive number of Claims as the Initial Decision Maker; .5 Evaluating substitutions proposed by the Owner or Contractor and making subsequent revisions to Instruments of Service resulting therefrom; or .6 To the extent the Architect's Basic Services are affected, providing Construction Phase Services 60 days after (1) the date of Substantial Completion of the Work or (2) the anticipated date of Substantial Completion identified in Initial Information, whichever is earlier. § 4.3.3 The Architect shall provide Construction Phase Services exceeding the limits set forth below as Additional Services. When the limits below are reached, the Architect shall notify the Owner: .1 two ( 2 ) reviews of each Shop Drawing, Product Data item, sample and similar submittal of the Contractor .2 fifty ( 50 ) visits to the site by the Architect over the duration of the Project during construction .3 twenty ( 20 ) inspections for any portion of the Work to determine whether such portion of the Work is substantially complete in accordance with the requirements of the Contract Documents .4 two ( 2 ) inspections for any portion of the Work to determine final completion § 4.3.4 If the services covered by this Agreement have not been completed within six ( 6 ) months of the estimated substantial completion date set out in Section 1.2 of this Agreement, through no fault of the Architect, extension of the Architect's services beyond that time shall be compensated as Additional Services. ARTICLE 5 OWNER'S RESPONSIBILITIES § 5.1 Unless otherwise provided for under this Agreement, the Owner shall provide information in a timely manner regarding requirements for and limitations on the Project, including a written program which shall set forth the Owner's objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements. Within 15 days after receipt of a written request from the Architect, the Owner shall furnish the requested information as necessary and relevant for the Architect to evaluate, give notice of or enforce lien rights. § 5.2 The Owner shall establish and periodically update the Owner's budget for the Project, including (1) the budget for the Cost of the Work as defined in Section 6.1; (2) the Owner's other costs; and, (3) reasonable contingencies related to all of these costs. If the Owner significantly increases or decreases the Owner's budget for the Cost of the Work, the Owner shall notify the Architect. The Owner and the Architect shall thereafter agree to a corresponding change in the Project's scope and quality. Init. AIA Document 8101 - —2007 (formerly B161— — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAa Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 10 this AIA® Document, or any portion of It, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 0611212014 under Order No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (3B9ADA2C) § 5.3 The Owner shall identify a representative authorized to act on the Owner's behalf with respect to the Project. The Owner shall render decisions and approve the Architect's submittals in a timely manner in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. § 5.4 The Owner shall furnish surveys to describe physical characteristics, legal limitations and utility locations for the site of the Project, and a written legal description of the site. The surveys and legal information shall include, as applicable, grades and lines of streets, alleys, pavements and adjoining property and structures; designated wetlands; adjacent drainage; rights -of -way, restrictions, easements, encroachments, zoning, deed restrictions, boundaries and contours of the site; locations, dimensions and necessary data with respect to existing buildings, other improvements and trees; and information concerning available utility services and lines, both public and private, above and below grade, including inverts and depths. All the information on the survey shall be referenced to a Project benchmark. § 5.5 The Owner shall furnish services of geotechnical engineers, which may include but are not limited to test borings, test pits, determinations of soil bearing values, percolation tests, evaluations of hazardous materials, seismic evaluation, ground corrosion tests and resistivity tests, including necessary operations for anticipating subsoil conditions, with written reports and appropriate recommendations. § 5.6 The Owner shall coordinate the services of its own consultants with those services provided by the Architect. Upon the Architect's request, the Owner shall famish copies of the scope of services in the contracts between the Owner and the Owner's consultants. The Owner shall furnish the services of consultants other than those designated in this Agreement, or authorize the Architect to furnish them as an Additional Service, when the Architect requests such services and demonstrates that they are reasonably required by the scope of the Project. The Owner shall require that its consultants maintain professional liability insurance as appropriate to the services provided. § 5.7 The Owner shall famish tests, inspections and reports required by law or the Contract Documents, such as structural, mechanical, and chemical tests, tests for air and water pollution, and tests for hazardous materials. § 5.8 The Owner shall furnish all legal, insurance and accounting services, including auditing services, that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests. § 5.9 The Owner shall provide prompt written notice to the Architect if the Owner becomes aware of any fault or defect in the Project, including errors, omissions or inconsistencies in the Architect's Instruments of Service. § 5.10 Except as otherwise provided in this Agreement, or when direct communications have been specially authorized, the Owner shall endeavor to communicate with the Contractor and the Architect's consultants through the Architect about matters arising out of or relating to the Contract Documents. The Owner shall promptly notify the Architect of any direct communications that may affect the Architect's services. § 5.11 Before executing the Contract for Construction, the Owner shall coordinate the Architect's duties and responsibilities set forth in the Contract for Construction with the Architect's services set forth in this Agreement. The Owner shall provide the Architect a copy of the executed agreement between the Owner and Contractor, including the General Conditions of the Contract for Construction. § 5.12 The Owner shall provide the Architect access to the Project site prior to commencement of the Work and shall obligate the Contractor to provide the Architect access to the Work wherever it is in preparation or progress. ARTICLE 6 COST OF THE WORK § 6.1 For purposes of this Agreement, the Cost of the Work shall be the total cost to the Owner to construct all elements of the Project designed or specified by the Architect and shall include contractors' general conditions costs, overhead and profit. The Cost of the Work does not include the compensation of the Architect, the costs of the land, rights -of -way, financing, contingencies for changes in the Work or other costs that are the responsibility of the Owner. § 6.2 The Owner's budget for the Cost of the Work is provided in Initial Information, and may be adjusted throughout the Project as required under Sections 5.2, 6.4 and 6.5. Evaluations of the Owner's budget for the Cost of the Work, the preliminary estimate of the Cost of the Work and updated estimates of the Cost of the Work prepared by the Architect, represent the Architect's judgment as a design professional. It is recognized, however, that neither InlL AIA Document B101- —2007 (formerly B151--1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAa Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 11 this AIAe Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order No.4594859925 which expires on 0611212015, and is not for resale. User Notes: (3B9ADA2C) the Architect nor the Owner has control over the cost of labor, materials or equipment; the Contractor's methods of determining bid prices; or competitive bidding, market or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Owner's budget for the Cost of the Work or from any estimate of the Cost of the Work or evaluation prepared or agreed to by the Architect. § 6.3 In preparing estimates of the Cost of Work, the Architect shall be permitted to include contingencies for design, bidding and price escalation; to determine what materials, equipment, component systems and types of construction are to be included in the Contract Documents; to make reasonable adjustments in the program and scope of the Project; and to include in the Contract Documents alternate bids as may be necessary to adjust the estimated Cost of the Work to meet the Owner's budget for the Cost of the Work. The Architect's estimate of the Cost of the Work shall be based on current area, volume or similar conceptual estimating techniques. If the Owner requests detailed cost estimating services, the Architect shall provide such services as an Additional Service under Article 4. § 6.4 If the Bidding or Negotiation Phase has not commenced within 90 days after the Architect submits the Construction Documents to the Owner, through no fault of the Architect, the Owner's budget for the Cost of the Work shall be adjusted to reflect changes in the general level of prices in the applicable construction market. § 6.5 If at any time the Architect's estimate of the Cost of the Work exceeds the Owner's budget for the Cost of the Work, the Architect shall make appropriate recommendations to the Owner to adjust the Project's size, quality or budget for the Cost of the Work, and the Owner shall cooperate with the Architect in making such adjustments. § 6.6 If the Owner's budget for the Cost of the Work at the conclusion of the Construction Documents Phase Services is exceeded by the lowest bona fide bid or negotiated proposal, the Owner shall .1 give written approval of an increase in the budget for the Cost of the Work; .2 authorize rebidding or renegotiating of the Project within a reasonable time; .3 terminate in accordance with Section 9.5; .4 in consultation with the Architect, revise the Project program, scope, or quality as required to reduce the Cost of the Work; or .5 implement any other mutually acceptable alternative. § 6.7 If the Owner chooses to proceed under Section 6.6.4, the Architect, without additional compensation, shall modify the Construction Documents as necessary to comply with the Owner's budget for the Cost of the Work at the conclusion of the Construction Documents Phase Services, or the budget as adjusted under Section 6.6.1. The Architect's modification of the Construction Documents shall be the limit of the Architect's responsibility under this Article 6. ARTICLE 7 COPYRIGHTS AND LICENSES § 7.1 The Architect and the Owner warrant that in transmitting Instruments of Service, or any other information, the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project. If the Owner and Architect intend to transmit Instruments of Service or any other information or documentation in digital form, they shall endeavor to establish necessary protocols governing such transmissions. § 7.2 The Architect and the Architect's consultants shall be deemed the authors and owners of their respective Instruments of Service, including the Drawings and Specifications, and shall retain all common law, statutory and other reserved tights, including copyrights. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect's consultants. § 7.3 Upon execution of this Agreement, the Architect grants to the Owner a nonexclusive license to use the Architect's Instruments of Service solely and exclusively for purposes of constructing, using, maintaining, altering and adding to the Project, provided that the Owner substantially performs its obligations, including prompt payment of all sums when due, under this Agreement. The Architect shall obtain similar nonexclusive licenses from the Architect's consultants consistent with this Agreement. The license granted under this section permits the Owner to authorize the Contractor, Subcontractors, Sub - subcontractors, and material or equipment suppliers, as well as the Owner's consultants and separate contractors, to reproduce applicable portions of the Instruments of Service solely Init. AIA Document 1311011- - 2007 (formerly 8161 TM — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 12 this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible / under the law. This Document was produced by AIA software at 17:15:51 on 0611212014 under Order No.4594859925 which expires on 06112/2015, and is not for resale. User Notes: (3B9ADA2C) and exclusively for use in performing services or construction for the Project. If the Architect rightfully terminates this Agreement for cause as provided in Section 9.4, the license granted in this Section 7.3 shall terminate. (Paragraph Deleted) § 7.4 Except for the licenses granted in this Article 7, no other license or right shall be deemed granted or implied under this Agreement. The Owner shall not assign, delegate, sublicense, pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect. Any unauthorized use of the Instruments of Service shall be at the Owner's sole risk and without liability to the Architect and the Architect's consultants. ARTICLE 8 CLAIMS AND DISPUTES § 8.1 GENERAL § 8.1.1 The Owner and Architect shall commence all claims and causes of action, whether in contract, tort, or otherwise, against the other arising out of or related to this Agreement in accordance with the requirements of the method of binding dispute resolution selected in this Agreement within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Architect waive all claims and causes of action not commenced in accordance with this Section 8.1.1. § 8.1.2 To the extent damages are covered by property insurance, the Owner and Architect waive all rights against each other and against the contractors, consultants, agents and employees of the other for damages, except such rights as they may have to the proceeds of such insurance as set forth in AIA Document A201 -2007, General Conditions of the Contract for Construction. The Owner or the Architect, as appropriate, shall require of the contractors, consultants, agents and employees of any of them similar waivers in favor of the other parties enumerated herein. § 8.1.3 The Architect and Owner waive consequential damages for claims, disputes or other matters in question arising out of or relating to this Agreement. This mutual waiver is applicable, without limitation, to all consequential damages due to either party's termination of this Agreement, except as specifically provided in Section 9.7. § 8.2 MEDIATION § 8.2.1 Any claim, dispute or other matter in question arising out of or related to this Agreement shall be subject to mediation as a condition precedent to binding dispute resolution. If such matter relates to or is the subject of a lien arising out of the Architect's services, the Architect may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by binding dispute resolution. § 82.2 The Owner and Architect shall endeavor to resolve claims, disputes and other matters in question between them by mediation which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of the Agreement. A request for mediation shall be made in writing, delivered to the other party to the Agreement, and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of a complaint or other appropriate demand for binding dispute resolution but, in such event, mediation shall proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. If an arbitration proceeding is stayed pursuant to this section, the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings. § 8.2.3 The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. § 8.2.4 If the parties do not resolve a dispute through mediation pursuant to this Section 8.2, the method of binding dispute resolution shall be the following: (Check the appropriate box. If the Owner and Architect do not select a method of binding dispute resolution below, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, the dispute will be resolved in a court of competent jurisdiction.) [ ] Arbitration pursuant to Section 8.3 of this Agreement Init. AIA Document B101--2007 (formerly B761 TM — 19971. Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Lew and International Treaties. Unauthorized reproduction or distribution of 13 this AIM Document, or any portion of i4 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible t under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order NoA594859925 which expires on 06/1212015, and is not for resale. User Notes: (3B9ADA2C) [ ] Litigation in a court of competent jurisdiction [ X ] Other (Specify) Per Professional Services Agreement, Section 15. § 8.3 ARBITRATION § 8.3.1 If the parties have selected arbitration as the method for binding dispute resolution in this Agreement, any claim, dispute or other matter in question arising out of or related to this Agreement subject to, but not resolved by, mediation shall be subject to arbitration which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of this Agreement. A demand for arbitration shall be made in writing, delivered to the other party to this Agreement, and filed with the person or entity administering the arbitration. § 8.3.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the claim, dispute or other matter in question would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the claim, dispute or other matter in question. § 8.3.2 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof. § 8.3.3 The award rendered by the arbitrator(s) shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. § 8.3.4 CONSOLIDATION OR JOINDER § 8.3.4.1 Either party, at its sole discretion, may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that (1) the arbitration agreement governing the other arbitration permits consolidation; (2) the arbitrations to be consolidated substantially involve common questions of law or fact; and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s). § 8.3.42 Either party, at its sole discretion, may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration, provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent. § 8.3.4.3 The Owner and Architect grant to any person or entity made a party to an arbitration conducted under this Section 8.3, whether by joinder or consolidation, the same rights of joinder and consolidation as the Owner and Architect under this Agreement. ARTICLE 9 TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect's option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days' written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Architect shall be paid all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the [nit. AIA Document 8101 91 -2007 (formerly 11161* — 1997). Copydght O 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and Into manorial Trestles. Unauthorized reproduction or distribution of 14 this AIA® Document, or any portion of it may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible ) under the law. This document was produced by AM software at 17:15:51 on 06/12/2014 under Order No.4594859925 which expires on 06112/2015, and is not for resale. User Notes: (3B9ADA2C) interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days' written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days' written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days' written notice to the Architect for the Owner's convenience and without cause. § 9.6 In the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior to termination, together with Reimbursable Expenses then due and all Termination Expenses as defined in Section 9.7. § 9.7 Termination Expenses are in addition to compensation for the Architect's services and include expenses directly attributable to termination for which the Architect is not otherwise compensated. § 9.8 The Owner's rights to use the Architect's Instruments of Service in the event of a termination of this Agreement are set forth in Article 7 and Section 11.9. ARTICLE 10 MISCELLANEOUS PROVISIONS § 10.1 This Agreement shall be governed by the law of the place where the Project is located, except that if the parties have selected arbitration as the method of binding dispute resolution, the Federal Arbitration Act shall govern Section 8.3. § 102 Terms in this Agreement shall have the same meaning as those in AIA Document A201-2007, General Conditions of the Contract for Construction. § 10.3 The Owner and Architect, respectively, bind themselves, their agents, successors, assigns and legal representatives to this Agreement. Neither the Owner nor the Architect shall assign this Agreement without the written consent of the other, except that the Owner may assign this Agreement to a lender providing financing for the Project if the lender agrees to assume the Owner's rights and obligations under this Agreement. § 10.4 If the Owner requests the Architect to execute certificates, the proposed language of such certificates shall be submitted to the Architect for review at least 14 days prior to the requested dates of execution. If the Owner requests the Architect to execute consents reasonably required to facilitate assignment to a lender, the Architect shall execute all such consents that are consistent with this Agreement, provided the proposed consent is submitted to the Architect for review at least 14 days prior to execution. The Architect shall not be required to execute certificates or consents that would require knowledge, services or responsibilities beyond the scope of this Agreement. § 10.5 Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of a third party against either the Owner or Architect. § 10.6 Unless otherwise required in this Agreement, the Architect shall have no responsibility for the discovery, presence, handling, removal or disposal of, or exposure of persons to, hazardous materials or toxic substances in any form at the Project site. § 10.7 The Architect shall have the right to include photographic or artistic representations of the design of the Project among the Architect's promotional and professional materials. The Architect shall be given reasonable access to the completed Project to make such representations. However, the Architect's materials shall not include the Owner's confidential or proprietary information if the Owner has previously advised the Architect in writing of the specific information considered by the Owner to be confidential or proprietary. The Owner shall provide professional credit for the Architect in the Owner's promotional materials for the Project. [nit. AIA Document B101- —2007 (formerly 13161- — 19 97). Copyright G 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 15 this AIA- Document, or any portion of It may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 17:15:51 on 06/1212014 under Order No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (3B9ADA2C) § 10.8 If the Architect or Owner receives information specifically designated by the other party as "confidential" or "business proprietary," the receiving party shall keep such information strictly confidential and shall not disclose it to any other person except to (1) its employees, (2) those who need to know the content of such information in order to perform services or construction solely and exclusively for the Project, or (3) its consultants and contractors whose contracts include similar restrictions on the use of confidential information. ARTICLE 11 COMPENSATION § 11.1 For the Architect's Basic Services described under Article 3, the Owner shall compensate the Architect as follows: (Insert amount of or basis for, compensation) $550,000.00 § 11.2 For Additional Services designated in Section 4. 1, the Owner shall compensate the Architect as follows: (Insert amount of or basis for, compensation. If necessary, list speck services to which particular methods of compensation apply.) None at time of execution. § 11.3 For Additional Services that may arise during the course of the Project, including those under Section 4.3, the Owner shall compensate the Architect as follows: (Insert amount of or basis for, compensation.) See Section 4.2 § 11.4 Compensation for Additional Services of the Architect's consultants when not included in Section 11.2 or 11.3, shall be the amount invoiced to the Architect plus percent( %), or as otherwise stated below: As negotiated. § 11.5 Where compensation for Basic Services is based on a stipulated sum or percentage of the Cost of the Work, the compensation for each phase of services shall be as follows: Schematic Design Phase thirteen percent ( 13 %) Design Development Phase twenty percent ( 20 %) Construction Documents thirty six percent ( 36 %) Phase Bidding or Negotiation Phase two percent ( 2 e /a) Construction Phase twenty nine percent ( 29 %) Total Basic Compensation one hundred percent ( 100 %) § 11.6 When compensation is based on a percentage of the Cost of the Work and any portions of the Project are deleted or otherwise not constructed, compensation for those portions of the Project shall be payable to the extent services are performed on those portions, in accordance with the schedule set forth in Section 11.5 based on (1) the lowest bona fide bid or negotiated proposal, or (2) if no such bid or proposal is received, the most recent estimate of the Cost of the Work for such portions of the Project. The Architect shall be entitled to compensation in accordance with this Agreement for all services performed whether or not the Construction Phase is commenced. § I V The hourly billing rates for services of the Architect and the Architect's consultants, if any, are set forth below. The rates shall be adjusted in accordance with the Architect's and Architect's consultants' normal review practices. (If applicable, attach an exhibit of hourly billing rates or insert them below) Init. AIA Iwcument 6101 ° — 2007 (formerly 8151 TM — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of 16 this AIA® Document, or any portion of it, may result in severe civil and criminal penahies, and will be prosecuted to me maximum extent possible / under the law. This Document was produced by AIA software at 17:15:51 on 06/1212014 under Ober No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (069ADA2C) Employee or Category Rate Lump sum fee of $550,000.00 § 11.8 COMPENSATION FOR REIMBURSABLE EXPENSES § 11.8.1 Reimbursable Expenses are in addition to compensation for Basic and Additional Services and include expenses incurred by the Architect and the Architect's consultants directly related to the Project, as follows: .1 Transportation and authorized out -of -town travel and subsistence; .2 Long distance services, dedicated data and communication services, teleconferences, Project Web sites, and extranets; .3 Fees paid for securing approval of authorities having jurisdiction over the Project; A Printing, reproductions, plots, standard form documents; .5 Postage, handling and delivery; .6 Expense of overtime work requiring higher than regular rates, if authorized in advance by the Owner; .7 Renderings, models, mock -ups, professional photography, and presentation materials requested by the Owner; .8 Architect's Consultant's expense of professional liability insurance dedicated exclusively to this Project, or the expense of additional insurance coverage or limits if the Owner requests such insurance in excess of that normally carried by the Architect's consultants; .9 All taxes levied on professional services and on reimbursable expenses; .10 Site office expenses; and .11 Other similar Project- related expenditures. § 11.8.2 For Reimbursable Expenses the compensation shall be the expenses incurred by the Architect and the Architect's consultants plus percent ( %) of the expenses incurred. As negotiated with Owner. Owner to contract directly with printing service bureau. See item "D" - Fee Scope Analysis of EXHBIT A § 11.9 COMPENSATION FOR USE OF ARCHITECT'S INSTRUMENTS OF SERVICE If the Owner terminates the Architect for its convenience under Section 9.5, or the Architect terminates this Agreement under Section 9.3, the Owner shall pay a licensing fee as compensation for the Owner's continued use of the Architect's Instruments of Service solely for purposes of completing, using and maintaining the Project as follows: $0.00 11.9.1 Compensation for Architect's services in the event of Termination: Termination expenses do not include an amount for the Architect's anticipated profit on the value of the services not performed by the Architect. Notwithstanding anything to the contrary in this agreement, Owner shall not be liable to provide compensation to the Architect for any services unless said services are actually provided. § 11.10 PAYMENTS TO THE ARCHITECT § 11.10.1 An initial payment of 5% or twenty two thousand five hundred ($ 22,500.00 ) shall be made upon execution of this Agreement and is the minimum payment under this Agreement. It shall be credited to the Owner's account in the final invoice. § 11.10.2 Unless otherwise agreed, payments for services shall be made monthly in proportion to services performed. Payments are due and payable upon presentation of the Architect's invoice. Amounts unpaid thirty ( 30 ) days after the invoice date shall bear interest at the rate entered below, or in the absence thereof at the legal rate prevailing from time to time at the principal place of business of the Architect. (Insert rate of monthly or annual interest agreed upon.) one point five % 1.5 % per month. § 11.10.3 The Owner shall not withhold amounts from the Architect's compensation to impose a penalty or liquidated damages on the Architect, or to offset sums requested by or paid to contractors for the cost of changes in the Work unless the Architect agrees or has been found liable for the amounts in a binding dispute resolution proceeding. Init. AIA Document 13101 " —2007 (formerly 13161 TM — 1997). Copyright ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U.S. Copyright Law and Intemational Treaties. Unauthorized reproduction or distribution of 17 this AIA® Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This Document was produced by AIA software at 17:15:51 on 06/1212014 under Order No.4594859925 which expires on 06/1212015, and is not for resale. User Notes: (3139ADA2C) § 11.10.4 Records of Reimbursable Expenses, expenses pertaining to Additional Services, and services performed on the basis of hourly rates shall be available to the Owner at mutually convenient times. ARTICLE 12 SPECIAL TERMS AND CONDITIONS Special terms and conditions that modify this Agreement are as follows: See EXHIBIT A - Fee Scope Analysis ARTICLE 13 SCOPE OF THE AGREEMENT § 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect. § 13.2 This Agreement is comprised of the following documents listed below: .1 AIA Document B101TM -2007, Standard Form Agreement Between Owner and Architect .2 AIA Document E201TM' -2007, Digital Data Protocol Exhibit, if completed, or the following: .3 Other documents: (List other documents, if arty, including Exhibit A, Initial Information, and additional scopes of service, if any, formingpart of the Agreement.) This Agroment egered *o as of the day and year first written above. OWNER Init. AIA Document B10191— 2007 (formerly, 1211161^— 1997). Copydght ®1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible 7 8 / under the law. This document was produced by AIA software at 17:15:51 on 06/12/2014 under Order N0.4594859925 which expires on 0611212015, and is not for resale. User Notes: (3S8ADA2C) L T E R E N C E L T H O R N H I L L E A R C H I T E C T EXHIBIT B - I Authorization for Additional Services Terence L. Thornhill Architect, Inc. P.S. / Pasco Police Community Services Building Project Name: Pasco Police CSB Agreement No: ASA 1.0 Project No: 214 -019 Date: Additional Services The following additional items of work on the project reference above have been or will be provided by Terence L. Thornhill Architect, Inc. P.S. These Additional Services are a supplement to the project scope contained in TLTA's existing Fee Proposal and Letter of Agreement for this Project, dated All other General Conditions of said Agreement remain in full force and effect The original contract for design and documentation services for the Pasco Police Community Services Building was intended for the design of the facility. That design included scope items contained within the original contract- Since design work has commenced, additionai services (time & materials) are necessary beyond the original scope. To complete these tasks it is expected that an additional fee of +/- $00.00 will be necessary. Payment for Additional Services Unless otherwise noted below, TLTA will provide these Additional Services on a time and materials basis, using TLTA's standard billing rates for a total amount of $00.00 Verbal Authorization Terence L. Thornhill Architect, Inc. P.S. was verbally directed to provide these Additional Services by: (name of Owner's representative. Terence L. Thornhill Architect, Inc. P.S. Terence L. Thornhill, AIA Date President Pasco Police Community Services Building Owner's Representative 9 2 2 1 S A N D I F U R PARKWAY S U I T E A , P A S C O , WA 99 3 0 1 PHONE (509)547 -8854 FAX (509)547 -8912 WWW.TLT ARCH. C 0 M Date TERELTH -01 TCHAMPLIN ACORO CERTIFICATE OF LIABILITY INSURANCE `-� DAT 61912 DIYYYY) 6/9/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsements). PRODUCER Richland OFFice Pa newest Insurance, Inc. Ric Bradley Blvd. Richland, WA 99352 CONTACT NAME: A"P EnO, 509 946 -6167 we No : 509 946 -0715 ADDRESS: PAS01227257 INSURERS AFFORDING COVERAGE NAICd INSURER A: Zurich North American Surety $ 1,000,00 INSURED INSURER a: Travelers Casualty & Surety Co 19038 INSURER C: E 10,00 Terence L. Thornhill, Architac INSURERD: PERSONAL B ADV INJURY 9221 Sandifur Parkway Ste. A Pasco, WA 99301 - _ NS IURERE: INSURER F: E 2,000,00 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. I�TR TYPE OF INSURANCE IN L POLICY NUMBER UWD YEP MW UNITS A X COMMERCUU.GENERAL LIABILITY CLAIMS -MADE FI OCCUR VIA Stop Gap PAS01227257 10/07/2013 10107/2014 EACH OCCURRENCE $ 1,000,00 P E;I Escoo $ 1,000,0 X MED EXP (Any we pamon E 10,00 PERSONAL B ADV INJURY $ 1,000,00 GENL AGGREGATE LIMIT APPLIES PER X POLICY 1:1 JE6 D LOC OTHER. GENERALAGGREGATE E 2,000,00 PRODUCTS - COMPIOPAGG E 2,000,00 $ A AUTOMOBILE X LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS HIRED AUTOS X NON -LIMED AUTOS PAS01227257 10107/2013 1010712014 COMBINED SINGLE LIMIT Ea emdara $ 1,000,00 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE PerecedeM $ $ UMBRELLA LUIS EXCESS LIAB OCCUR CLAIMS -MADE EACHOCCURRENCE E_ _ $ _ _ AGGREGATE DED J I RETENTION $ WORKERS COMPENSATION ANDEMPLOYERS'UABILITY YIN ANY PROPRIETOWARTNEWE %ECUTIVE OFFCER EMBER EXCLUDED? ❑ (Mandatory In NM) N ea, desembe under DESCRIPTION OF OPERATIONS below NIA PER OTH- STATUTE ER E.L. EACH ACCIDENT $ E.L. DISEASE -EA EMPLOYE $ E.L. DISEASE - POLICY LIMIT $ B Architect Prof Liab 108487294 08127/2013 08/2712014 Policy Limit 1,000,0 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached N more space Is required) City of Pasco 525 N. 3rd Pasco, WA 98301 AL,UKU 25 (2014/U1) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. A^U/TTKOOW/ZnE' D RREEP�RESENTATIVE q ` e4„ V ©1 The ACORD name and logo are registered marks of ACORD reserved. CERTIFICATE OF LIABILITY INSURANCE R059 6/9 20019 ) THIS CERTIFICATEIS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, E)ITEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must be endorsed. I SUBROGATIONIS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endomement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). U S BANCORP INS SERV INC MNRB0178 480241 P: (800) 771 -9055 F: (800) 771 -6080 PO BOX 33015 SAN ANTONIO TX 78265 oornACr (M.NU.E4 (800) 771 -9055 wc,wf (800) 771 -6080 AA'DDRESS: B PMIRMFDRDNBDDYERABE NAICR AsURERA: Hartford Casualty Ins Co. 29424 ANIOND TERENCE L THORNHILL ARCHITECT INC PS DBA TERENCE L THORNHILL ARCHITECT INC P 9221 SANDIFUR PKWY STE A PASCO WA 99301 INSURERS: CONMERCLAL GENERAL UABILRY INSURESC: INgUREe D: INSURERS: FACH OCCURRENCE INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. lNSk rYPEOPINSVBM'CH "As XUAR IblA:YMINABR PO UCTEFF POUCFAIT rfMJTX CONMERCLAL GENERAL UABILRY FACH OCCURRENCE g DAMAGETD RENTED CLAIMS -MADE ❑OCCUR PREMIBES Ea aRGRINB MFD IXP(Arry erN{gmn) g PERSONALdADV IWIXtY g GENT AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE PRODUCTS - COMPIOP AGO g POLICY JEOT ❑ LOC OTHER: MLE LIAe000, 000 NJURY(sW TBODLLY A qHIUROEMD LL ONSCHEDULED ATOS AUTOS 48 UEG FY8112 05/07/2014 05/07/2015 BODILY 1hLKWV ryer amaem) PROS DAMAGE g AVTO X AUTOS EO UMBRELLA L14e OCCUR EACH OCCURRENCE AGGREGATE EXCESS LMB CLNMSM E Os ReTkNndrti S waxreAV rnuraNSlnmv AND £MN.OYERS'lJA[r /Jlf ANY PROPRIETORMARTNERJEXECUTNE YIN MA NfE lm TM SiA E.L. EACH ACCIDENT g OFFICERMEMSER EXCLUDED? fMRRdktTv In NN) ❑ WA EL DISEASE- EAEMPLOYEE B yes, deswbe under E.L. DISEASE - POLICY LIMIT g DESCRIPTION OF OPERATIONS W. OES CRWnON (ACORD 101. Addaoml Remarks SeWdkM. my W eesN,W ffs" smm R muhwI) Those usual to the Insured's Operations. HOLDER ATION 01988 -2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014101) The ACORD name and logo are registered marks of ACORD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUnIORIlED REPRESENTAT VE L525 ty of Pasco N 3RD AVE SCO, WA 99301 01988 -2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014101) The ACORD name and logo are registered marks of ACORD Washington State Department of Labor & Industries TERENCE L THORNHILL ARCHITECT INC Owner or tradesperson KATHLEEN THORNHILL Doing business as TERENCE L THORNHILL ARCHITECT WA UBI No. 601 679 200 Workers' comp 9221 SANDIFER PKWY STE A PASCO, WA 99301 Governing persons KATHLEEN R THORNHILL TERENCE L THORNHILL; Do you know if the business has employees? If so, verify the business is up -to -date on workers' comp premiums. This company has multiple workers' comp accounts. Active accounts L &I Account ID Account is current. 862,612 -01 Doing business as TERENCE L THORNHILL ARCHITECT Estimated workers reported Quarter 1 of Year 2014 "4 to 6 Workers' L &I account representative T1 / TYRONE COLEMAN (360)902 -4807 - Email: COTI235@lni.wa.gov Workplace safety and health No inspections during the previous 6 year period. Washington state Dept. of Labor & Industries. Use of this site is subject to the law s of the St i. ` cce,,s Ad&Wa.INT10,10m